Terms of service

Effective date: 23 August 2026. These terms are issued by Globitude Travels, Two Horizon Center, WeWork, Golf Course Road, DLF City Phase 5, Gurugram, Haryana 122002, India ("Globitude Travels & Tech", "we"). Questions: info@flightcampaign.com.

Part A: Website terms

Use of this website

By using flightcampaign.com you accept these terms. You may browse the site, share links to our pages and use the enquiry form for genuine business enquiries. You may not scrape the site at scale, attempt to access the administration area, submit false or abusive enquiries, or use the site to distribute malware or unsolicited messages.

Our content

The text, diagrams, code samples and design of this site belong to Globitude Travels & Tech unless stated otherwise. You may quote short passages with a link to the source page. You may not republish whole pages or guides without our written permission.

No warranty for information

Our guides and service pages are general information about travel technology and online marketing, not legal, tax, financial or regulatory advice. Platform policies, supplier terms and commission structures change often; check the current source before relying on anything here. We make reasonable efforts to keep content accurate but give no warranty that it is complete or up to date. See our editorial policy.

Links to third parties

The site links to platform policy centres, supplier documentation and other external sites. We do not control them and are not responsible for their content, availability or privacy practices; a link is not an endorsement. Guide pages may carry labelled third-party advertising; see our disclaimer.

Trademarks

Amadeus, Sabre, Travelport, Skyscanner, Kayak, Google, Meta and all other product, airline, GDS and supplier names on this site are trademarks of their respective owners. They are used descriptively to explain what we integrate with and do not imply affiliation, sponsorship or endorsement. Globitude Travels & Tech is not affiliated with Meta Platforms, Inc.

Enquiries

Sending an enquiry does not create a contract. Any indicative figures we mention in a reply are estimates until confirmed in a written proposal. Personal data in enquiries is handled as described in our privacy policy.

Part B: General terms of engagement for services

These terms apply to every project unless a signed agreement says otherwise. Where they conflict with a signed proposal or master services agreement, the signed document prevails.

Scope

The scope of each project is defined by a written proposal listing the pages, modules, integrations, deliverables and exclusions. Work begins when you accept the proposal in writing (email is sufficient) and the first milestone payment is received. Anything not listed is out of scope; change requests are quoted separately before work starts and may affect the timeline.

Quotes and payment

Quotes are fixed-price for the scope stated and valid for the period shown on the proposal. Payment milestones, currency, taxes (including GST where applicable) and accepted methods are set out in each agreement; typically a deposit on acceptance, a payment on staging approval and the balance before go-live. We may pause work on overdue accounts. Source code and credentials are released on receipt of the final payment.

Client responsibilities

• Supplier agreements. You obtain and maintain your own contracts, credentials and certifications with airlines, GDSs, consolidators, hotel suppliers, affiliate networks, payment gateways and other third parties. We integrate with what you have access to; we cannot obtain supplier access on your behalf.
• Licences and registrations. You are responsible for the business registrations, travel-industry licences, tax registrations and insurance required in the markets you sell to.
• Content and legal compliance. You supply, or approve, the text, fares, fees, images, logos and legal pages for your site and you are responsible for their accuracy and for compliance with consumer protection, advertising, data protection and industry rules in each market. We flag issues we notice, but we do not give legal advice.
• Timely input. Approvals, content and supplier test credentials are needed at the points in the project plan; delays on your side extend the timeline.
• Lawful use. You will not use anything we build to impersonate an airline or supplier, to mislead travellers about who they are dealing with or what they will pay, or to breach platform policies. We may decline or stop work we reasonably believe would do so.

Intellectual property

On receipt of full payment, you own the website, portal or application code written specifically for your project, along with your domain, content, data, design files and supplier configurations. Globitude Travels & Tech retains ownership of its pre-existing tools, frameworks, libraries, components and know-how, and grants you a perpetual, non-exclusive licence to use them as part of your delivered system. Third-party and open-source components remain under their own licences. We may describe the project in general terms in our portfolio unless you ask us not to.

Confidentiality

Each party keeps the other's non-public business information confidential, including supplier terms, pricing, credentials, customer data and source code, uses it only for the project, and continues to do so after the project ends. This does not cover information that is public, already known to the receiving party, or required to be disclosed by law. A separate non-disclosure agreement is available on request.

Limitation of liability

We perform the services with reasonable skill and care. To the extent permitted by law, our total liability for any claim arising out of a project is limited to the fees paid for that project, and we are not liable for indirect or consequential loss, including lost profit, lost bookings, advertising spend, supplier penalties or account suspensions. Nothing here limits liability for fraud or anything that cannot be limited by law.

No guarantee of rankings, ad approvals or revenue

We build to current search engine guidelines and advertising policies, but rankings, advertising account approvals, AdSense acceptance, supplier certifications and revenue depend on third parties and on your own business. We do not guarantee any of them.

Support and third-party changes

Warranty on delivered work covers defects reported within the period stated in the proposal. Changes by suppliers, platforms, hosting providers or browsers after delivery are not defects; fixing them is covered by a support plan or quoted separately.

Termination

Either party may end a project by written notice if the other materially breaches these terms and does not fix the breach within 14 days of being told. You may also end a project for convenience; completed milestones are then payable, work in progress is invoiced pro rata, and we hand over what has been delivered and paid for. We may end a project if continuing would breach the lawful-use clause above.

Governing law and disputes

These terms and every engagement are governed by the laws of India. The courts at Gurugram, Haryana have exclusive jurisdiction, subject to any arbitration clause in a signed agreement. [TO CONFIRM: jurisdiction and dispute-resolution wording with your lawyer, including whether to add arbitration under the Arbitration and Conciliation Act 1996.] The parties will try to resolve disagreements by discussion before taking formal steps.

General

If any clause is unenforceable, the rest remains in effect. Neither party is liable for delay caused by events outside its reasonable control. These terms and the written proposal are the whole agreement for a project. We may update Part A by posting a new version here; Part B changes apply to proposals issued after the change.

Related: privacy policy, disclaimer, about us.